建筑装饰工程施工合
Contract
发包方（简称甲方）
Party A
承包方（简称乙方）：海巧点装饰设计限公司
Party B ipoint design (Inspiration Point Design)
根<中华民国合法><中华民国消费者权益保护法><中华民国价格法><海市合格式条款监督条例><海市建筑市场理条例>关法律法规规定原结合工程具体情况甲乙双方等愿协商致基础达成协议遵守
According to PRC Contract Law Law on the Protection of Consumer Interests PRC Price Law Shanghai Supervision of Contract Terms Shanghai Construction Market Management Regulations as well as other laws and regulations relevant to the specific circumstances of this project parties A and B have hereby equally and voluntarily entered into the following agreement executed on the basis of mutual respect
概况
OVERVIEW
1 甲方装饰物业系合法物业
Party A is the owner of the property
2 乙方市工商行政理机关核准登记事装潢装修企业
Party B is approved and registered with the city industrial and commercial administrative organs as an
enterprise engaged in renovation and decoration
3 装饰施工点
Construction site
4 建筑结构： 建筑面积 方米施工面积 方米
Construction area total area (including stairwells and other common areas) m2 private living area m2
5 装饰施工容：住宅装饰详见附件<工程估价单>
Structure residential
6 承包方式详见附件<工程估价单>
Contractor engagement method See annex – (quotation)
7 总价款： 00元写(民币) 元整
Total price 00RMB in words 元整 Any changes in this price must be agreed by both parties in writing
8 工期 年 月 日开工 年 月 日前竣工工时总计 天含国家法定节假日乙方委派现场施工监理 先生联系方式
Period Start (year) (month) (day) Completion before (year) (month) (day) Total days (excluding national holidays) days Party B＇s on site construction supervisor will be
二关工程付款结算约定
TERMS OF PAYMENT
1 工程款付款方式
The payment schedule shall be as follows
付 款 时 间
Timing of Payments
付 款 时 间
Date (yyyymmdd)
Amount (RMB)
合签订60
After the contract is signed
油漆工进场前30
When half of the project period time has elapsed
家具灯具进场前5
Furniture of lamps and lanterns before the approach
验收合格五天5
Upon Acceptance of
the completion of the project
增加工程项目100
Project changes
签订工程项目变更单100
Date of signing for the project change
空调工程项目100
Air conditioning project
家具工程项目100
Furniture engineering
三关材料供应约定
AGREEMENT ON THE SUPPLY OF MATERIALS
1 乙方提供材料：乙方供应材料设备符合设计施工求应禁止已工程造成损失乙方负责甲方增加材料甲方供应应符合列规定：
Material provided by Party B Any materials or equipment supplied by Party B which do not meet the design and construction requirements are prohibited Any extra materials requested by Party A which were not in the original design must be paid for by Party A
2 甲方提供材料：拟补充附件<甲方提供材料设备表>
甲方负责采购供应材料设备应符合设计施工求合格产品应时供应现场乙方发现甲方提供材料设备质量问题规格差异应时甲方提出甲方求造成工程损失责甲方承担甲方供应材料时抵达现场乙方负责保
Material provided by Party A (see the annex Table of Materials to be provided by the Owner) If Party A acquires materials for the project it should first check with Party B that the materials match to the design requirements and once the materials are in the care of Party B then Party B is responsible for the materials If Party A requires some materials which do not fit to the design then it shall be the responsibility of Party A to pay any additional costs incurred by Party B
四关工程质量验收约定
FULFILMENT OF THIS AGREEMENT
1 工程应符合<建筑装饰工程技术规程>市建设行政部门制定方标准＼质量评定验收标准
The execution of this project must be consistent with the Architectural and Engineering Rules of the city administrative departments responsible for the development of buildings and local standards and quality evaluation acceptance criteria
2 工程乙方进行设计提供施工图纸式两份双方签字确认
Party B must provide a duplicate copy of the construction designs and drawings and both copies should be signed by both parties
3 甲方提供材料设备质量合格影响工程质量返工费甲方承担工期相应延
If materials provided by Party A for the construction do not meet the necessary requirements Party A shall bear responsibility for any resulting delays in the completion in the project
4 乙方原造成质量事返工费乙方承担
If the quality of Party B＇s work results in any accidents the liability for such accidents shall be the responsibility of Party B
5 施工程中甲方提出设计修改意见增减工程项目须提前乙方联系双方签订<工程项目变更单>方进行该项目施工影响工程竣工日期责甲方承担甲方私施工员商定更改施工容增加施工项目引起切果甲方负乙方造成损失甲方应予赔偿
If during the construction Party A wishes to propose a change to the design he should sign a Change of Project with Party B and must assume responsibility for resulting delays or increase in costs If Party A secretly attempts to change to design directly with the construction personnel and this action causes loss to Party B then Party A must compensate Party B for this loss
6 工程验收：乙方负责理隐蔽工程中间工程检查验收手续乙方组织专门员进行验收切理隐蔽工程中间工程质量乙方负责
The standard of work It is the responsibility of Party B to make sure that all construction works are carried out to the requirements of the design and to make sure that all internal walls and hidden construction parts are to the required standard
7 工程竣工：乙方完工应通知甲方验收甲方应竣工日组织验收办理验收移交手续双方签<工程质量验收单>果甲方规定时间组织验收须时通知乙方定验收日期通竣工验 收甲方应承认原竣工日期承担造成乙方费相关费
Project completion Party B must notify Party A when the project is complete and ready for inspection by Party A After inspection both parties must sign an Engineering Quality Acceptance document If Party A is not available to inspect the construction site on the completion date he must notify Party B of the soonest available date Where Party A is not available on the completion date to retake custody of the location he must pay any extra costs incurred by Party B
8 工程保修期年工程竣工验收甲乙双方签署<工程保修单>保修单实行保修保修期年竣工验收签章日起算
One year warranty After completion of the work and signing of the Single Warranty there shall be a one year warranty on the construction
五关安全生产防火约定
SAFE PRODUCTION AND FIRE REGULATIONS
1 施工图纸施工说明应符合防火 防事求包括电气线路等道畅通合格乙方施工中应采取必安全防护消防措施保障作业员相邻关系安全防止相邻单位道堵塞渗漏水停电物品毁坏等事发生
Construction drawings and construction must be in line with fire prevention regulations and accident prevention requirements This includes electrical circuits and pipelines Party B shall take measures to ensure the safety of workers and neighbors at the constructions site and must prevent leakage of water interruptions of power and damage to property
2 施工中涉改变房屋结构拆改承重墙加楼（）面荷载甲方物业理部门提出申请建设行政部门批准方施工
Any changes to the housing structure or demolition or alteration to load bearing walls or increase in floor load must first be approved by the building property management before construction begins
3 双方款项均应出具正规收发票备查验结算
Both parties must provide money exchange receipts and invoices
六 事项
OTHER MATTERS
1甲方工作
Party A
1 甲方应开工前确认施工图纸腾出足够施工空间清影响施工障碍物甲方乙方提供施工需水电等必备条件说明注意事项
When Party A confirms the preconstruction and construction drawings he must also make sure there is sufficient space available at the construction site for construction to take place Party A must make sure that Party B has everything necessary on site for completion of the construction particularly electricity and water
2 做施工中时公部位操作影响邻里关系等协调工作
Party A must take care of the public relations in the construction site area – particularly with the neighbors
2 乙方工作
Party B
1 参加甲方召集现场交底
Party B must be available to attend meetings organized by Party A
2 乙方求组织施工保质保量期完成施工务
Party B must follow the construction plans and the construction must be durable and must meet the scheduled completion date
七违约责
LIABILITY FOR BREACH OF CONTRACT
1 甲方原导致延期开工中途停工工期延
If Party A causes any delays to the completion of this project then the scheduled completion date should be adjusted accordingly
2 乙方原逾期竣工逾期天乙方甲方支付工程造价01‰(写千分)违约金
If Party B causes any delay to the completion of this project then Party B must pay to Party A a fee of 01‰
( in words 11000)of the total overall project fee for each day beyond the scheduled completion date
3 甲方未办理关手续强行求乙方拆改原建筑承重结构设备线发生损失事（包括罚款）甲方负责承担责
If Party A instructs Party B to make any alterations to a load bearing wall and Party A has not sought and received permission from the building property management Party A shall be responsible for any resulting costs and shall indemnify Party B for any additional expenses incurred
4 乙方擅拆改原建筑承重结构设备线发生损失事（包括罚款）乙方负责承担责
If Party B makes any unauthorized changes to load bearing walls or building pipelines and such changes result in damages or loss it shall be the responsibility of Party B to pay for such loss
5 工程未办理验收结算手续甲方提前擅动工程成品造成法验收损失甲方负责承担责
Party A shall be responsible for any extra costs incurred due to his use of the property before the final completion meeting and signing of the Engineering Quality Acceptance document
八纠纷处理方式
DISPUTES
1 工程质量双方发生争议时合文关行业协会申请调解区县建设行政部门消费者协会投诉
If there is a dispute between the parties this contract should be submitted to the relevant trade association for mediation and also to the host district and county building departments in charge of administrative complaints or to consumer associations
2 事愿通协商调解解决协商调解成时合约定海仲裁委员会申请仲裁民法院提起诉讼
if after negotiation mediation andor consultation the parties have failed to reach an agreement then the dispute
should besubmitted to theShanghai Arbitration Commissionfiled as a lawsuit
九合变更解
AMENDMENT AND TERMINATION
1合双方签字生效双方必须严格遵守方求变更合容解合约双方协商解决双方签字确认生效
After this contract is signed it must be strictly adhered to After the contract is signed neither party can leave the contract without agreement of the other party
2合签订工程转包
After this contract is signed the project shall not be subcontracted
3合式 两 份甲乙双方执 1 份合附件合组成部分具等法律效力
This contract will be printed and signed in duplicate and each party shall keep a copy
十约定
FINAL CLAUSES
1遇抗力素工期延
In the event of force majeure this contract will be delayed and resume as soon as practicably possible
2未合规定事项双方协商解决
If any matters arise which are not covered within this contract they shall be dealt with by mutual consultation between the two parties
十附件
ANNEX
1 <工程估价单>
Annex 1 Single Warranty
2办理施工进场手续费清单
Annex 2 Itemized expenditure list of Party B for the construction (eg waste removal fees charged by the property management)
3施工图纸做法说明
Annex 3 Construction drawings and practice notes
Party A (Chop) Party B (Chop) 海巧点装饰设计限公司
Corporation Company Owner (name) 廖娟英
Company Owner (name) Company Owner (name)
Project Leader Project Leader 王开锐
Address Address 姚虹路299弄12号1401
Post Code Post Code 201103
Phone Phone 54775839
Fax Fax 54775608
Bank Name 农行海市长宁区古北新区支行
Account Name 海巧点装饰设计限公司
Account Number 03382700040002751
Date 年 月 日 Date 年 月 日
文档香网(httpswwwxiangdangnet)户传
《香当网》用户分享的内容，不代表《香当网》观点或立场，请自行判断内容的真实性和可靠性！
该内容是文档的文本内容，更好的格式请下载文档
Contract
发包方（简称甲方）
Party A
承包方（简称乙方）：海巧点装饰设计限公司
Party B ipoint design (Inspiration Point Design)
根<中华民国合法><中华民国消费者权益保护法><中华民国价格法><海市合格式条款监督条例><海市建筑市场理条例>关法律法规规定原结合工程具体情况甲乙双方等愿协商致基础达成协议遵守
According to PRC Contract Law Law on the Protection of Consumer Interests PRC Price Law Shanghai Supervision of Contract Terms Shanghai Construction Market Management Regulations as well as other laws and regulations relevant to the specific circumstances of this project parties A and B have hereby equally and voluntarily entered into the following agreement executed on the basis of mutual respect
概况
OVERVIEW
1 甲方装饰物业系合法物业
Party A is the owner of the property
2 乙方市工商行政理机关核准登记事装潢装修企业
Party B is approved and registered with the city industrial and commercial administrative organs as an
enterprise engaged in renovation and decoration
3 装饰施工点
Construction site
4 建筑结构： 建筑面积 方米施工面积 方米
Construction area total area (including stairwells and other common areas) m2 private living area m2
5 装饰施工容：住宅装饰详见附件<工程估价单>
Structure residential
6 承包方式详见附件<工程估价单>
Contractor engagement method See annex – (quotation)
7 总价款： 00元写(民币) 元整
Total price 00RMB in words 元整 Any changes in this price must be agreed by both parties in writing
8 工期 年 月 日开工 年 月 日前竣工工时总计 天含国家法定节假日乙方委派现场施工监理 先生联系方式
Period Start (year) (month) (day) Completion before (year) (month) (day) Total days (excluding national holidays) days Party B＇s on site construction supervisor will be
二关工程付款结算约定
TERMS OF PAYMENT
1 工程款付款方式
The payment schedule shall be as follows
付 款 时 间
Timing of Payments
付 款 时 间
Date (yyyymmdd)
Amount (RMB)
合签订60
After the contract is signed
油漆工进场前30
When half of the project period time has elapsed
家具灯具进场前5
Furniture of lamps and lanterns before the approach
验收合格五天5
Upon Acceptance of
the completion of the project
增加工程项目100
Project changes
签订工程项目变更单100
Date of signing for the project change
空调工程项目100
Air conditioning project
家具工程项目100
Furniture engineering
三关材料供应约定
AGREEMENT ON THE SUPPLY OF MATERIALS
1 乙方提供材料：乙方供应材料设备符合设计施工求应禁止已工程造成损失乙方负责甲方增加材料甲方供应应符合列规定：
Material provided by Party B Any materials or equipment supplied by Party B which do not meet the design and construction requirements are prohibited Any extra materials requested by Party A which were not in the original design must be paid for by Party A
2 甲方提供材料：拟补充附件<甲方提供材料设备表>
甲方负责采购供应材料设备应符合设计施工求合格产品应时供应现场乙方发现甲方提供材料设备质量问题规格差异应时甲方提出甲方求造成工程损失责甲方承担甲方供应材料时抵达现场乙方负责保
Material provided by Party A (see the annex Table of Materials to be provided by the Owner) If Party A acquires materials for the project it should first check with Party B that the materials match to the design requirements and once the materials are in the care of Party B then Party B is responsible for the materials If Party A requires some materials which do not fit to the design then it shall be the responsibility of Party A to pay any additional costs incurred by Party B
四关工程质量验收约定
FULFILMENT OF THIS AGREEMENT
1 工程应符合<建筑装饰工程技术规程>市建设行政部门制定方标准＼质量评定验收标准
The execution of this project must be consistent with the Architectural and Engineering Rules of the city administrative departments responsible for the development of buildings and local standards and quality evaluation acceptance criteria
2 工程乙方进行设计提供施工图纸式两份双方签字确认
Party B must provide a duplicate copy of the construction designs and drawings and both copies should be signed by both parties
3 甲方提供材料设备质量合格影响工程质量返工费甲方承担工期相应延
If materials provided by Party A for the construction do not meet the necessary requirements Party A shall bear responsibility for any resulting delays in the completion in the project
4 乙方原造成质量事返工费乙方承担
If the quality of Party B＇s work results in any accidents the liability for such accidents shall be the responsibility of Party B
5 施工程中甲方提出设计修改意见增减工程项目须提前乙方联系双方签订<工程项目变更单>方进行该项目施工影响工程竣工日期责甲方承担甲方私施工员商定更改施工容增加施工项目引起切果甲方负乙方造成损失甲方应予赔偿
If during the construction Party A wishes to propose a change to the design he should sign a Change of Project with Party B and must assume responsibility for resulting delays or increase in costs If Party A secretly attempts to change to design directly with the construction personnel and this action causes loss to Party B then Party A must compensate Party B for this loss
6 工程验收：乙方负责理隐蔽工程中间工程检查验收手续乙方组织专门员进行验收切理隐蔽工程中间工程质量乙方负责
The standard of work It is the responsibility of Party B to make sure that all construction works are carried out to the requirements of the design and to make sure that all internal walls and hidden construction parts are to the required standard
7 工程竣工：乙方完工应通知甲方验收甲方应竣工日组织验收办理验收移交手续双方签<工程质量验收单>果甲方规定时间组织验收须时通知乙方定验收日期通竣工验 收甲方应承认原竣工日期承担造成乙方费相关费
Project completion Party B must notify Party A when the project is complete and ready for inspection by Party A After inspection both parties must sign an Engineering Quality Acceptance document If Party A is not available to inspect the construction site on the completion date he must notify Party B of the soonest available date Where Party A is not available on the completion date to retake custody of the location he must pay any extra costs incurred by Party B
8 工程保修期年工程竣工验收甲乙双方签署<工程保修单>保修单实行保修保修期年竣工验收签章日起算
One year warranty After completion of the work and signing of the Single Warranty there shall be a one year warranty on the construction
五关安全生产防火约定
SAFE PRODUCTION AND FIRE REGULATIONS
1 施工图纸施工说明应符合防火 防事求包括电气线路等道畅通合格乙方施工中应采取必安全防护消防措施保障作业员相邻关系安全防止相邻单位道堵塞渗漏水停电物品毁坏等事发生
Construction drawings and construction must be in line with fire prevention regulations and accident prevention requirements This includes electrical circuits and pipelines Party B shall take measures to ensure the safety of workers and neighbors at the constructions site and must prevent leakage of water interruptions of power and damage to property
2 施工中涉改变房屋结构拆改承重墙加楼（）面荷载甲方物业理部门提出申请建设行政部门批准方施工
Any changes to the housing structure or demolition or alteration to load bearing walls or increase in floor load must first be approved by the building property management before construction begins
3 双方款项均应出具正规收发票备查验结算
Both parties must provide money exchange receipts and invoices
六 事项
OTHER MATTERS
1甲方工作
Party A
1 甲方应开工前确认施工图纸腾出足够施工空间清影响施工障碍物甲方乙方提供施工需水电等必备条件说明注意事项
When Party A confirms the preconstruction and construction drawings he must also make sure there is sufficient space available at the construction site for construction to take place Party A must make sure that Party B has everything necessary on site for completion of the construction particularly electricity and water
2 做施工中时公部位操作影响邻里关系等协调工作
Party A must take care of the public relations in the construction site area – particularly with the neighbors
2 乙方工作
Party B
1 参加甲方召集现场交底
Party B must be available to attend meetings organized by Party A
2 乙方求组织施工保质保量期完成施工务
Party B must follow the construction plans and the construction must be durable and must meet the scheduled completion date
七违约责
LIABILITY FOR BREACH OF CONTRACT
1 甲方原导致延期开工中途停工工期延
If Party A causes any delays to the completion of this project then the scheduled completion date should be adjusted accordingly
2 乙方原逾期竣工逾期天乙方甲方支付工程造价01‰(写千分)违约金
If Party B causes any delay to the completion of this project then Party B must pay to Party A a fee of 01‰
( in words 11000)of the total overall project fee for each day beyond the scheduled completion date
3 甲方未办理关手续强行求乙方拆改原建筑承重结构设备线发生损失事（包括罚款）甲方负责承担责
If Party A instructs Party B to make any alterations to a load bearing wall and Party A has not sought and received permission from the building property management Party A shall be responsible for any resulting costs and shall indemnify Party B for any additional expenses incurred
4 乙方擅拆改原建筑承重结构设备线发生损失事（包括罚款）乙方负责承担责
If Party B makes any unauthorized changes to load bearing walls or building pipelines and such changes result in damages or loss it shall be the responsibility of Party B to pay for such loss
5 工程未办理验收结算手续甲方提前擅动工程成品造成法验收损失甲方负责承担责
Party A shall be responsible for any extra costs incurred due to his use of the property before the final completion meeting and signing of the Engineering Quality Acceptance document
八纠纷处理方式
DISPUTES
1 工程质量双方发生争议时合文关行业协会申请调解区县建设行政部门消费者协会投诉
If there is a dispute between the parties this contract should be submitted to the relevant trade association for mediation and also to the host district and county building departments in charge of administrative complaints or to consumer associations
2 事愿通协商调解解决协商调解成时合约定海仲裁委员会申请仲裁民法院提起诉讼
if after negotiation mediation andor consultation the parties have failed to reach an agreement then the dispute
should besubmitted to theShanghai Arbitration Commissionfiled as a lawsuit
九合变更解
AMENDMENT AND TERMINATION
1合双方签字生效双方必须严格遵守方求变更合容解合约双方协商解决双方签字确认生效
After this contract is signed it must be strictly adhered to After the contract is signed neither party can leave the contract without agreement of the other party
2合签订工程转包
After this contract is signed the project shall not be subcontracted
3合式 两 份甲乙双方执 1 份合附件合组成部分具等法律效力
This contract will be printed and signed in duplicate and each party shall keep a copy
十约定
FINAL CLAUSES
1遇抗力素工期延
In the event of force majeure this contract will be delayed and resume as soon as practicably possible
2未合规定事项双方协商解决
If any matters arise which are not covered within this contract they shall be dealt with by mutual consultation between the two parties
十附件
ANNEX
1 <工程估价单>
Annex 1 Single Warranty
2办理施工进场手续费清单
Annex 2 Itemized expenditure list of Party B for the construction (eg waste removal fees charged by the property management)
3施工图纸做法说明
Annex 3 Construction drawings and practice notes
Party A (Chop) Party B (Chop) 海巧点装饰设计限公司
Corporation Company Owner (name) 廖娟英
Company Owner (name) Company Owner (name)
Project Leader Project Leader 王开锐
Address Address 姚虹路299弄12号1401
Post Code Post Code 201103
Phone Phone 54775839
Fax Fax 54775608
Bank Name 农行海市长宁区古北新区支行
Account Name 海巧点装饰设计限公司
Account Number 03382700040002751
Date 年 月 日 Date 年 月 日
文档香网(httpswwwxiangdangnet)户传
《香当网》用户分享的内容，不代表《香当网》观点或立场，请自行判断内容的真实性和可靠性！
该内容是文档的文本内容，更好的格式请下载文档
